Mr Jeremy Glover

Jeremy Glover

Updates

Construction

How the 2017 FIDIC contract deals with time
United Kingdom | 29 October 2018

In 2017 the International Federation of Consulting Engineers (FIDIC) finally unveiled the Second Edition of the 1999 Rainbow Suite, Red, Yellow and Silver Books. This article examines how the FIDIC form deals with time and includes an appendix detailing the changes made to Clause 8, the primary clause which deals with time or 'Commencement, Delays and Suspension' from the original 1999 contract.

Victory House General Partner Ltd v RGB P&C Ltd
United Kingdom | 18 June 2018

An application was recently made to restrain notice being given of a winding-up petition which sought payment of some £820,000 following an adjudicator's decision in respect of goods supplied and services rendered for the development and conversion of Victory House. The adjudicator had rejected Victory House's argument that it was not liable to pay the sum identified in the interim application because the parties had entered into a memorandum of understanding which provided for other payments to be made.

Cleveland Bridge UK Ltd v Sarens (UK) Ltd
United Kingdom | 21 May 2018

CBUK and Sarens recently sought a determination, following an adjudicator's decision, of a dispute over the terms and interpretation of a subcontract. Sarens had been engaged by CBUK to provide cranes and other equipment for the installation of six bridges along the M6 link road. CBUK had been engaged as subcontractor to Costain under a modified NEC3 contract. The dispute was about what, if anything, CBUK and Sarens had agreed about the provision of liquidated damages.

Gosvenor London Ltd v Aygun Aluminium UK Ltd
United Kingdom | 14 May 2018

After Gosvenor agreed to perform certain cladding works for Aygun, disputes arose and Gosvenor applied to enforce an adjudicator's decision. Aygun accepted that adjudicators' decisions will be enforced by the courts, regardless of errors of fact or law, but alleged fraud on the part of Gosvenor, stating that "a substantial proportion" of the adjudication award had been based on sums which were fraudulently invoiced. However, no allegations of fraud had been raised in the adjudication proceedings.

Complying with instructions: Oil States Industries (UK) Ltd v Lagan Building Contractors Ltd
United Kingdom | 30 April 2018

In 2014 OSI and Lagan entered into a contract for the design and construction of a new production facility. During the course of the contract, OSI's agent issued certain instructions and in July 2016 OSI gave notice to Lagan that it was in default in failing to comply with four of these instructions. OSI said that Lagan did not remedy the default and accordingly gave notice of termination. In a preliminary hearing, Lagan held that two of the contract instructions had been invalid.

Claims for overhead and profit: Fluor Ltd v Shanghai Zhenhua Heavy Industry Co, Ltd
United Kingdom | 23 April 2018

In a recent judgment in an ongoing dispute about the quality of steel monopiles at an offshore wind farm, a judge had to consider claims for overhead and profit. The plaintiff had claimed a percentage for overheads at a rate of 4%, which the judge was reluctant to accept. While the judge suspected that the plaintiff may well have incurred increased overhead costs as a result of breaches of contract, he was not prepared "to pluck a figure out of the air".